Sylvester Williams Park Parking Lot Improvements
Washington County > Board of County Commissioners
Original Solicitation Links
Original Notices
SYLVESTER WILLIAMS PARK PARKING LOT PROJECT #50189421 NOTICE TO RECEIVE SEALED BIDS The Franklin County Board of County Commissioners will receive sealed bids from any qualified person, company or corporation interested in constructing: SYLVESTER WILLIAMS PARK PARKING LOT Project is located at Sylvester Williams Park on 10th Street in Apalachicola, Florida and consists of paving the existing parking lot, sidewalk construction and a proposed stormwater facility. Plans and specifications can be obtained by contacting Shannon Renfro at srenfro@dewberry.com, Dewberry Engineers, Inc., 324 Marina Drive, Port St. Joe, FL 32456. There is no charge for electronic plans. The bid must conform to Section 287.133(3) Florida Statutes, on public entity crimes. Completion date for this project will be 90 days from the date of the Notice to Proceed presented to the successful bidder. Liquidated damages for failure to complete the project on the specified date will be set at $250.00 per day. Please indicate on the envelope that this is a sealed bid, for SYLVESTER WILLIAMS PARK PARKING LOT. Bids will be received until 4:30 p.m. eastern time, on Monday, November 2nd, 2026, at the Franklin County Clerk's Office, Franklin County Courthouse, 33 Market Street, Suite 203, Apalachicola, Florida 32320-2317, and will be opened and read aloud on Wednesday, November 4th, 2026, at the County Commission meeting held at the Courthouse Annex Courtroom, 34 Forbes Street, Apalachicola, FL. A mandatory pre-bid meeting will be held at the project site on Friday, October 23rd, 2026, at 10:00 am eastern time. The Board of County Commissioners reserves the right to waive informalities in any bid, to accept and/or reject any or all bids, and to accept the bid that in their judgment will be in the best interest of Franklin County. All bids shall remain firm for a period of sixty days after the opening. All bidders shall comply with all applicable State and local laws concerning licensing registration and regulation of contractors doing business to the State of Florida. If you have any questions, please email Josh Stephens at jstephens@dewberry.com by 5:00 p.m. eastern time on Monday. October 26th, 2026. 09/30, 10/7, 2026 12654570
Contact
Submission Instructions
Description
Franklin County Board of County Commissioners is soliciting sealed bids for improvements at Sylvester Williams Park, including paving the existing parking lot, constructing sidewalks, and building a proposed stormwater facility. The project is a one-time construction effort with completion required within 90 days after the Notice to Proceed, and liquidated damages are $250 per day for late completion. Bids must comply with Section 287.133(3), Florida Statutes, concerning public entity crimes, as well as applicable state and local contractor licensing requirements. Bids must remain firm for 60 days after opening. A bid bond is required, and the bid envelope must be marked as a sealed bid for “SYLVESTER WILLIAMS PARK PARKING LOT.”
Classification Codes
Smart Codes
Specifications
Timeline
Requirements
- Bid Bond
Documents
| Title | Date Posted |
|---|---|
| ITB Sylvester Williams Park Parking Improvements | Sep 18, 2026 08:52 AM |
'Highway, Street, and Bridge Construction' Opportunities
The Texas Department of Transportation is seeking bids for roadway repairs on State Loop 375 in El P...
The City of Shreveport is seeking sealed or electronic bids for Montana Street Bridge Improvements, ...
The Oklahoma Department of Transportation is seeking bids for a construction project with a bid open...
The Town of Tecumseh is seeking a contractor to reconstruct Westlake Drive, with bids due October 22...
The Texas Department of Transportation is seeking bids for an overlay construction project on US 281...
The City of Cape Coral is seeking bids for the Caloosa Parkway Roadway Improvement project, with ele...
The Idaho Transportation Department is seeking sealed proposals for full-depth reconstruction of a r...
The Town of Clover is seeking sealed bids for the Bark River Road Improvement Project 2027 in Clover...
SMA Construction Services is accepting bids for an unspecified project for the Kewaunee County Highw...
The United Nations Development Programme is requesting quotations to construct a 280-meter concrete ...
Cadillac Asphalt is seeking bids for a road construction project on Fenton Rd, Grand Blanc Rd, I-75,...
Cadillac Asphalt is seeking a subcontractor for road construction on M-153 Frains Lake Rd to Napier ...
The Virginia Department of Transportation is seeking a prequalified contractor to construct the B23_...
The Virginia Department of Transportation is seeking a prequalified contractor for scenic trail cons...
The Virginia Department of Transportation is seeking a prequalified contractor for scenic trail cons...
Clinch County Board of Commissioners is seeking sealed bids for 4.71 miles of resurfacing improvemen...
Boh Bros. Construction Co., LLC is accepting bids for the DPW 823 Citywide Streets Major and Minor #...
The City of Las Vegas is seeking bids for Wyoming Avenue improvements between Industrial Road and La...
East Baton Rouge Parish is seeking bids for street construction work in Wimbledon Estates, Harveston...
Hancock County, Mississippi is soliciting sealed bids for construction of 11.819 miles of maintenanc...
The South Carolina Department of Transportation is soliciting electronic bids for highway constructi...
The Village of Merrillan is requesting sealed bids for improvements to a street segment from North H...
The City of Augusta, Georgia, is seeking bids for improvements to Greene Street between 5th Street a...
The Oklahoma Department of Transportation is soliciting bids for an unspecified transportation const...
Columbia County Board of Commissioners is seeking bids for furnishing materials, equipment, and labo...
Opportunities Near Tallahassee, Florida
The Leon County-City of Tallahassee Blueprint Intergovernmental Agency is seeking professional servi...
Leon County is seeking qualified vendors for continuing inspection, maintenance, repair, and replace...
The Florida Fish and Wildlife Conservation Commission is seeking a turnkey-ready 2026-or-newer Carol...
The School Board of Leon County, Florida, is seeking qualified vendors to provide electrical contrac...
The Florida Department of Children and Families is requesting information from vendors about data so...
The City of Tallahassee Electric and Gas Utility is seeking information from software vendors and co...
The Florida Department of Agriculture and Consumer Services is seeking a contractor for structural, ...
The Capital Region Transportation Planning Agency is seeking qualified consultants to conduct a six-...
The Florida Department of Health is seeking a single-source purchase of an EPA-approved automated de...
The Florida Department of Agriculture and Consumer Services intends to make a single-source purchase...
The Florida Department of Corrections is seeking an independent provider to design, implement, integ...
The Florida Department of Commerce is seeking sealed bids for commercial custodial services, includi...
The Florida Department of Commerce is seeking research, analysis, stakeholder engagement, and consul...
The Florida Office of Insurance Regulation is seeking a contractor to conduct a multi-state market c...
The Florida Department of Financial Services, Office of Financial Regulation, is seeking information...
The Florida Department of Financial Services, Office of Financial Regulation, is seeking information...
The Florida Department of Financial Services is seeking information from qualified vendors about med...
The Florida Department of Financial Services, Office of Insurance Regulation, is seeking a contracto...
The State of Florida, Department of Legal Affairs, Office of the Attorney General, is seeking a cont...
The Florida Department of State intends to purchase single-source maintenance and support for VR Sys...
The Florida Department of Education is seeking a contractor or contractors to provide a statewide mo...
The Florida Department of Transportation is seeking eight months of calibration, repair, maintenance...
The Florida Department of Transportation is seeking a contractor to administer Logo Sign Program ser...
The Florida Department of Transportation is seeking a contractor to administer, market, engineer, fa...
The Florida Department of Transportation intends to award Agile Access Control, Inc. a single-source...