Brick Campus Restroom Renovations
Ocean County Vocational Technical School
Original Solicitation Links
Contact
Submission Instructions
Description
The Board of Education of the Ocean County Vocational Technical School is soliciting sealed construction bids for proposed restroom renovations at the Ocean County Vocational Technical School Brick Campus. The project is subject to a Project Labor Agreement, prevailing-wage requirements, affirmative-action requirements, and New Jersey public-school contracting laws. Bidders must hold a valid New Jersey Public Works Contractor Registration Certificate and, for projects exceeding $20,000, provide the required state prequalification documentation, including a Prequalification Affidavit, Notice of Classification, Total Amount of Uncompleted Contracts Form, and related affidavit. A non-mandatory pre-bid meeting is scheduled at the project site. Bids require one original, one paper copy of all documents, and one electronic copy on a USB flash drive enclosed in the sealed envelope. For bids over $100,000, bid security must equal 10% of the total bid, capped at $20,000, and may be provided as a certified check, cashier’s check, or bid bond. The project is expected to begin on or about November 26, 2026, reach 100% completion within 120 calendar days after notice to proceed, and carry liquidated damages of $500 per day for late completion. The contract term is nine months from the date of bid award unless otherwise specified.
Classification Codes
Smart Codes
Specifications
Timeline
Requirements
- Bid Bond — 10%
Documents
Documents available via:
- Location - Office of the Architect — YEZZI ASSOCIATES, LLC, ARCHITECTS AND PLANNERS, 18 Washington Street, P.O. Box 1638, Toms River, NJ 08753
- Phone - 732-240-3433
'Commercial and Institutional Building Construction' Opportunities
Christa Construction, LLC is soliciting subcontractor and supplier bids for building trades for the ...
The U.S. Navy's NAVFAC Southwest is seeking qualified small-business sources for a potential five-ye...
BC Hydro is notifying potential proponents of commercial and office building construction procuremen...
Durham County is seeking a single-prime contractor to construct a 28,895-square-foot utilities admin...
Harris County is seeking a contractor for a four-courtroom Level 17 buildout at Annex 46, 1019 Congr...
Iowa State University is seeking bids for construction of a storage building and maintenance buildin...
McNeese State University is seeking bids for construction of a new maintenance and storage facility ...
The Pennsylvania Air National Guard is seeking sources for a $5 million to $10 million project to re...
The Town of Walpole is seeking bids for construction of the 2027-03A Route 1A Storage Building.
Mississippi State University is seeking bids for the re-bid construction of the Deer Outreach Buildi...
A project owner is seeking M/WBE bids for the construction project at 10-38 Beach 21st Street in Que...
The U.S. Air Force is seeking small-business construction contractors for an IDIQ multiple-award con...
A contractor is seeking M/WBE bids for a construction project at 4411 Avenue D in Brooklyn, New York...
The State of Illinois is seeking a contractor to construct a maintenance building and demolish an ex...
The Department of Veterans Affairs is planning a $500,000–$1,000,000 project to construct an approxi...
Sourcewell, a Minnesota cooperative purchasing agency, is seeking construction contractors for IDIQ ...
The U.S. Army Corps of Engineers is seeking industry feedback on delivery methods, feasibility, and ...
The Mississippi Bureau of Building, Grounds and Real Property Management is seeking sealed bids for ...
Cortland Enlarged City School District is seeking bids for renovations to Coyne Hall at 4969 Onondag...
McNeese State University is seeking sealed bids for construction of campus gateways at its Lake Char...
Madison County Schools is seeking sealed single-prime proposals to construct a new visitor locker ro...
The Town of Gilbert is seeking Construction Manager at Risk firms for the expansion of its Advocacy ...
Con Tech Building Systems, Inc. is soliciting bids from certified MWBE and SDVOB firms for renovatio...
School District No. 72 is seeking bids to supply, deliver, and construct two childcare centres at sc...
Johnson County Government is seeking bids for the JC Park Banquet Hall project, with submissions due...
Opportunities Near Monmouth County, New Jersey
The Joint Meeting of Essex and Union Counties is seeking qualification statements from firms experie...
The Tinton Falls School District is seeking a licensed provider to deliver comprehensive school-base...
The Delaware River Port Authority is seeking proposals for a two-year contract to supply office supp...
The New Jersey Department of Children and Families is seeking providers for statewide five-bed out-o...
The New Jersey Water Supply Authority is requesting statements of qualifications and technical propo...
The Joint Meeting of Essex and Union Counties is seeking qualification statements from firms experie...
The New Jersey Economic Development Authority is requesting a bidder's proposal and fee schedule for...
The New Jersey Department of Transportation is seeking a design-build contractor to plan, install, o...
The New Jersey Turnpike Authority is seeking expressions of interest for environmental compliance se...
The State of New Jersey, on behalf of the New Jersey Department of Environmental Protection, is seek...
The New Jersey Department of Transportation is seeking construction inspection services for Maintena...
The State of New Jersey is seeking contractors to provide aircraft maintenance, avionics, engines, p...
The Delaware Valley Regional Planning Commission is seeking transportation planners and traffic engi...
The Joint Meeting of Essex and Union Counties is requesting proposals from qualified respondents to ...
Monmouth Ocean Educational Services Commission is seeking proposals for Internet access and data tra...
Rowan University is seeking snow, ice, sleet, and hail removal, salting, and emergency response serv...
The New Jersey Department of Human Services, Office of New Americans, is seeking nonprofit or govern...
The New Jersey Department of Transportation is seeking construction inspection services for the Rout...
The U.S. Army is seeking offers for FY2027–FY2031 WC864 ball powder under solicitation W15QKN26RA085...
The New Jersey Department of Human Services, Division of Aging Services, is seeking nonprofit or gov...
Monmouth County is seeking nonprofit providers for youth delinquency prevention, mentoring, diversio...
The State of New Jersey, on behalf of the New Jersey Department of Corrections, is seeking licensed ...
The Joint Meeting of Essex and Union Counties is seeking qualification statements from attorneys to ...
NJ Transit is seeking up to four contracts for systemwide architectural and engineering services and...
The New Jersey Economic Development Authority is requesting a task-order response under Reference RF...