Prequalification for 201 Rivermoor Street Project

The City of Boston Public Facilities Department is seeking statements of qualifications to prequalify general and subcontractors for the 201 Rivermoor Street Project, estimated at $14,464,434.00.

City of Boston


General
Open
7253
Aug 14, 2026 12:00 PM
$14,464,434.00
Request for Information (RFI)
Local
Ask AI about this solicitation
Original Solicitation Links
Original Notices

72140000 ADVERTISEMENT CITY OF BOSTON PUBLIC FACILITIES DEPARTMENT (PFD) Request for Qualifications PFD - 201 Rivermoor Street Project # 7253 Contact Information: PFD Bid Counter Bid.info@boston.gov (617)-635-4809 Pursuant to M.G.L. c.149, sections 44D ½ and 44D ¾, the City of Boston acting by its Public Facilities Commission, through its Director of the Public Facilities Department (PFD), hereinafter referred to as the Awarding Authori- ty, hereby requests statements of qualifications (SOQ) to prequalify subcontractors and general contractors for the above-entitled project with a construction estimate of $14,464,434.00. This Request for Qualifications (RFQ) is the first part of a two step process. Based on the SOQs received in this Phase I, The Awarding Authority will select respondents it deems to be prequalified in accordance with the criteria set forth in the RFQ. In Phase II, the prequalified respondents will be in- vited to submit bids in response to an IF

Contact
bid.info@boston.gov
+16176354809
2 Center Plaza, Boston, MA, USA
Description

The City of Boston, through its Public Facilities Department (PFD), is issuing this Request for Qualifications (RFQ) to prequalify subcontractors and general contractors for the 201 Rivermoor Street Project. The estimated construction cost for this project is $14,464,434.00. This RFQ represents the first phase of a two-step procurement process. Based on the submitted statements of qualifications (SOQs), the PFD will select respondents who meet the prequalification criteria outlined in the RFQ. In the second phase, prequalified respondents will be invited to submit bids for the project.

Classification Codes
NAICS236220Commercial and Institutional Building Construction
PSCY1AZCONSTRUCTION OF OTHER ADMINISTRATIVE FACILITIES AND SERVICE BUILDINGS
Smart Codes
construction project managementsubcontractor prequalificationpublic facilities construction
'Commercial and Institutional Building Construction' Opportunities
SCAP Campus Building Trades Subcontractor Bids

Christa Construction, LLC is soliciting subcontractor and supplier bids for building trades for the ...

Due in 9 days•Christa Construction, LLC
Metropolitan San Diego General Construction IDIQ JOC

The U.S. Navy's NAVFAC Southwest is seeking qualified small-business sources for a potential five-ye...

Due in 10 days•United States of America > DEPT OF DEFENSE > DEPT OF THE NAVY > NAVFACSYSCOM SOUTHWEST (NAVFAC SOUTHWEST SW)
Notice to Vendors of Upcoming Procurement Opportunities

BC Hydro is notifying potential proponents of commercial and office building construction procuremen...

Due in 26 days•British Columbia > BC Hydro
Utilities Administration Building Construction

Durham County is seeking a single-prime contractor to construct a 28,895-square-foot utilities admin...

Due in 4 days•Durham County > Purchasing Division of Finance
Annex 46 Four-Courtroom Buildout

Harris County is seeking a contractor for a four-courtroom Level 17 buildout at Annex 46, 1019 Congr...

Due in 29 days•Harris County > Office of the County Engineer
Reiman Gardens Storage and Maintenance Building Construction

Iowa State University is seeking bids for construction of a storage building and maintenance buildin...

Due in 18 days•Iowa State University
New Maintenance and Storage Facility Construction

McNeese State University is seeking bids for construction of a new maintenance and storage facility ...

Due in 2 days•McNeese State University > Purchasing Department
Building 78 Facility Repair and Addition

The Pennsylvania Air National Guard is seeking sources for a $5 million to $10 million project to re...

Due in 6 days•United States of America > DEPT OF DEFENSE > DEPT OF THE ARMY > W7NX USPFO ACTIVITY PA ARNG (USPFO PA PROCUREMENT)
Route 1A Storage Building Construction

The Town of Walpole is seeking bids for construction of the 2027-03A Route 1A Storage Building.

Due in 11 days•Town of Walpole
Deer Outreach Building Construction

Mississippi State University is seeking bids for the re-bid construction of the Deer Outreach Buildi...

Due in 2 days•Mississippi State University > Office of Procurement and Contracts
10-38 Beach 21st Street Construction Project

A project owner is seeking M/WBE bids for the construction project at 10-38 Beach 21st Street in Que...

Due in 4 days•Project Owner
Hill Air Force Base Multiple-Award Construction Contract V

The U.S. Air Force is seeking small-business construction contractors for an IDIQ multiple-award con...

Due in about 2 months•United States of America > DEPT OF DEFENSE > DEPT OF THE AIR FORCE > FA8201 AFSC OL H PZIO (AIR FORCE SUSTAINMENT CENTER)
4411 Avenue D Construction Project

A contractor is seeking M/WBE bids for a construction project at 4411 Avenue D in Brooklyn, New York...

Due in 4 days•New York
Maintenance Building Construction and Existing Structure Demolition

The State of Illinois is seeking a contractor to construct a maintenance building and demolish an ex...

State of Illinois
Covered Office Space Construction

The Department of Veterans Affairs is planning a $500,000–$1,000,000 project to construct an approxi...

Due in 2 days•United States of America > VETERANS AFFAIRS, DEPARTMENT OF > NATIONAL CEMETERY ADMIN (36C786) (CENTRALIZED CONTRACTING DIVISION)
Indefinite Delivery Indefinite Quantity Construction Services

Sourcewell, a Minnesota cooperative purchasing agency, is seeking construction contractors for IDIQ ...

Due in 11 days•Minnesota > Sourcewell
B-21 Field Training Detachment Facility Market Research

The U.S. Army Corps of Engineers is seeking industry feedback on delivery methods, feasibility, and ...

Due in 12 days•United States of America > DEPT OF DEFENSE > DEPT OF THE ARMY > W076 ENDIST FT WORTH (KO CONTRACTING DIVISION)
Department of Corrections E Building Phase 1 Construction

The Mississippi Bureau of Building, Grounds and Real Property Management is seeking sealed bids for ...

Due in 16 days•State of Mississippi > Department of Finance and Administration > Bureau of Building, Grounds and Real Property Management
Coyne Hall Renovations

Cortland Enlarged City School District is seeking bids for renovations to Coyne Hall at 4969 Onondag...

Due in 10 days•Cortland Enlarged City School District
Campus Gateway Construction

McNeese State University is seeking sealed bids for construction of campus gateways at its Lake Char...

Due in 3 days•McNeese State University > Purchasing Department
Madison County High School Visitor Locker Room Facility

Madison County Schools is seeking sealed single-prime proposals to construct a new visitor locker ro...

Due in 18 days•Madison County School System
Advocacy Center Expansion Construction Management

The Town of Gilbert is seeking Construction Manager at Risk firms for the expansion of its Advocacy ...

Due in 23 days•Town of Gilbert > Development Services > Public Works
Coyne Hall Renovations

Con Tech Building Systems, Inc. is soliciting bids from certified MWBE and SDVOB firms for renovatio...

Due in 10 days•Con Tech Building Systems, Inc.
Two Childcare Centre Construction

School District No. 72 is seeking bids to supply, deliver, and construct two childcare centres at sc...

Due in 19 days•School District No. 72
JC Park Banquet Hall Project

Johnson County Government is seeking bids for the JC Park Banquet Hall project, with submissions due...

Due in about 17 hours•Johnson County > Johnson County Regional Interagency Operating Network (JCRION) Consortium
Opportunities In Massachusetts
Live-Agent Visual Interpretation Services

The Massachusetts Bay Transportation Authority is seeking a provider for software-based, real-time v...

Due in about 1 month•Massachusetts Bay Transportation Authority
Dunnage Bar Manufacturing Capability Statement

The U.S. Department of Transportation's Volpe National Transportation Systems Center is seeking capa...

Due in 5 days•United States of America > TRANSPORTATION, DEPARTMENT OF > OFFICE OF THE SECRETARY > 6913G6 VOLPE NATL. TRANS. SYS CNTR (OFFICE OF ACQUISITIONS)
Commercial Office Space Lease near Hanscom Air Force Base

The United States Air Force is seeking capability statements from property owners, brokers, or autho...

Due in 10 days•United States of America > DEPT OF DEFENSE > DEPT OF THE AIR FORCE > FA2287 LOOKING GLASS NEXT WVG
South Boston Waterfront Parking Management

The Massachusetts Port Authority is seeking management and revenue collection services for South Bos...

Due in about 1 month•Massachusetts Port Authority
Walk-In Cooler and Freezer Replacement

The U.S. Geological Survey is seeking a small business to remove and replace an existing walk-in coo...

Due in 12 days•United States of America > INTERIOR, DEPARTMENT OF THE > DEPARTMENTAL OFFICES > USGS CONTRACTING ACTIVITY
Chemical Nutrient Analysis Laboratory Services

The U.S. Army is seeking an ISO/IEC 17025-accredited laboratory to perform chemical nutrient analyse...

Due in 11 days•United States of America > DEPT OF DEFENSE > DEPT OF THE ARMY > W6QK ACC-APG NATICK (NATICK DIVISION)
Combat Boot Sock Manufacturing Sources Sought

The U.S. Marine Corps is seeking sources capable of manufacturing high-performance combat boot socks...

Due in 12 days•United States of America > DEPT OF DEFENSE > DEPT OF THE ARMY > W6QK ACC-APG NATICK (NATICK DIVISION)
FY2027 Service Incentive Notice of Intent

The Massachusetts Executive Office of Elder Affairs is seeking responses to a fiscal year 2027 Servi...

Due in 12 days•Massachusetts > Executive Office of Aging & Independence
Virtual School Enrollment and Marketing Support

The Education Cooperative's Massachusetts Connections Academy is seeking enrollment and marketing su...

Due in 26 days•Massachusetts > The Education Cooperative
Learning Management System

Massachusetts Connections Academy is seeking an integrated learning management system for approximat...

Due in 26 days•Massachusetts > The Education Cooperative
Vet Center Outreach Printing and Distribution

The U.S. Government Publishing Office is seeking a contractor to print and deliver 447,539 Vet Cente...

Due in 3 days•United States of America > UNITED STATES GOVERNMENT PUBLISHING OFFICE > Customer Services
Out-of-State Medical Resident Reproductive Health Training Grants

The Massachusetts Department of Public Health is offering up to $1,000,000 in grants to two or three...

Due in about 1 month•Massachusetts > Department of Public Health > Bureau of Community Health and Prevention
Automated Fuel Management Terminal Replacement

The U.S. Air Force is seeking a small-business contractor to remove an obsolete QTPod M3000 and furn...

Due in 19 days•United States of America > DEPT OF DEFENSE > DEPT OF THE AIR FORCE > FA2835 AFLCMC HANSCOM PZI (AIR FORCE LIFE CYCLE MANAGEMENT CENTER)
West Intermediate Window and Door Replacement Project Management

The Town of Wilmington, Massachusetts, is seeking a qualified owner's project manager for its West I...

Due in 18 days•Town of Wilmington
Boston Antenna Site Lease

The Drug Enforcement Administration is seeking a sole-source site lease in Boston, Massachusetts, fr...

Due in 2 days•United States of America > JUSTICE, DEPARTMENT OF > DRUG ENFORCEMENT ADMINISTRATION > OFFICE ACQUISITION MANAGEMENT
Housing Authority Building and Site Improvements

Dukes County Regional Housing Authority is seeking DCAMM-certified contractors for approximately $59...

Due in 18 days•Massachusetts > Dukes County Regional Housing Authority
On-Call Architectural and Engineering Services

The Town of Randolph Department of Public Works is requesting qualifications from consultants for no...

Due in 25 days•Town of Randolph
Inmate Medical and Mental Health Services

The Middlesex Sheriff's Office is seeking a vendor to provide inmate medical and mental health servi...

Due in about 1 month•Massachusetts > Middlesex Sheriff's Office
Airport Commercial Advertising Concession

The Massachusetts Port Authority is seeking an experienced advertising company to design, fabricate,...

Due in 3 months•Massachusetts Port Authority
On-Call Water Tank Cleaning and Inspection Services

The Town of Rockport is seeking on-call cleaning, inspection, chlorination, and sediment-removal ser...

Due in 11 days•Rockport
On-Call HVAC Maintenance

The Town of Rockport is seeking an on-call contractor for heating, ventilation, and air-conditioning...

Due in 18 days•Rockport
Middle/High School Waterproofing, Dampproofing, and Caulking

The Town of Millis is seeking prequalified trade contractors for waterproofing, dampproofing, and ca...

Due in 19 days•Town of Millis
Enrollment Operations Program Management

The University of Massachusetts Lowell is seeking an Enrollment Operations Program Manager to provid...

Due in 19 days•University of Massachusetts > University of Massachusetts Lowell > Division of Graduate, Online & Professional Studies
Chiller Plant Operations and Maintenance Engineering Review

The University of Massachusetts Amherst is seeking an engineering consultant to review and improve t...

Due in 26 days•University of Massachusetts Amherst > Facilities & Campus Services
Weapon Control System Spares and Support Equipment

The U.S. Navy's Strategic Systems Programs is seeking capability statements from firms able to procu...

Due in 2 days•United States of America > DEPT OF DEFENSE > DEPT OF THE NAVY > PAE STRATEGIC SYSTEMS PROGRAMS (SSP)
Comments
Correspondences
Custom Fields