North Mesa Bike Park and Amenities Design-Build

Los Alamos County is seeking qualifications for a design-build contractor for the North Mesa Bike Park and related amenities, with shortlisted firms later invited to submit proposals.

Los Alamos County


General
Open
DBP27-05
Oct 27, 2026 08:00 PM
Sep 22, 2026 12:00 PM
Request for Quote/Qualifications (RFQ)
Local
Ask AI about this solicitation
Original Solicitation Links
Original Notices
Santa Fe New Mexican — Santa Fe, New MexicoSep 22, 2026

LEGAL #95758 COUNTY OF LOS ALAMOS DESIGN-BUILD SOLICITATION DBP27-05 Design-Build for North Mesa Bike Park and Amenities The solicitation for this Design-Build Project will be conducted in two phases in accordance with County Code Sec. 31-177. Phase 1 will be a Request for Qualifications and Phase 2 will be a Request for Proposals, limited to the short-listed persons from Phase 1 who are invited to submit proposals. Phase 1 sealed responses submitted electronically through the County's Procurement Portal, subject to the conditions set forth in the solicitation documents, will be received until October 27, 2026, 2:00 p.m. Mountain Time for this solicitation. Registering for a vendor account to the County's Procurement Portal is free and information and instructions to register to download solicitation docume- nts and submit Responses through the County's Procurement Portal can be found online at the following web address: https:// www.losalamosnm. gov/Doi

Submission Instructions
Description

Los Alamos County is conducting a two-phase design-build procurement for the North Mesa Bike Park and related amenities. Phase 1 is a Request for Qualifications; only shortlisted firms invited from Phase 1 may participate in Phase 2, a subsequent Request for Proposals. Phase 1 responses must be submitted electronically through the County's Procurement Portal. Vendor registration is required to download the solicitation documents and submit a response. The stated Phase 1 deadline is October 27, 2026, at 2:00 p.m. Mountain Time.

Classification Codes
NAICS237310Highway, Street, and Bridge Construction
PSCY1PACONSTRUCTION OF RECREATION FACILITIES (NON-BUILDING)
Smart Codes
bike park constructiondesign-build constructionrecreational amenities
Specifications
Service
Timeline
Oct 27, 2026 08:00 PM-Phase 1 Response Deadline
Documents
'Highway, Street, and Bridge Construction' Opportunities
State Loop 121 New Road Construction

The Texas Department of Transportation is seeking bids to construct a 1.99-mile segment of State Loo...

Due in 1 day•Texas Department of Transportation
Montana Street Bridge Improvements

The City of Shreveport is seeking sealed or electronic bids for Montana Street Bridge Improvements, ...

Due in 17 days•Lafayette Consolidated Government > Purchasing Division
Highway Construction Project

The Oklahoma Department of Transportation is seeking bids for a construction project with a bid open...

Due in 25 days•State of Oklahoma > Department of Transportation
Westlake Drive Reconstruction

The Town of Tecumseh is seeking a contractor to reconstruct Westlake Drive.

Due in 11 days•Town of Tillsonburg
Caloosa Parkway Roadway Improvement

The City of Cape Coral is seeking bids for the Caloosa Parkway Roadway Improvement project, with ele...

Due in 14 days•City of Cape Coral
FM 791 Roadway Rehabilitation

The Texas Department of Transportation is seeking bids to rehabilitate FM 791 and associated roadway...

Due in 1 day•Texas Department of Transportation
US 69 Roadway Rehabilitation

The Texas Department of Transportation is seeking a contractor to rehabilitate the existing US 69 ro...

Due in 1 day•State of Texas > Texas Department of Transportation
Travis County IH 35 Highway Improvement

The Texas Department of Transportation is seeking bids for a $400,424,745.50 highway improvement pro...

Due in 29 days•Texas Department of Transportation
Hickory LA 48–Mounes Project

Boh Bros. Construction Co., LLC is accepting bids for the Hickory project associated with LA 48 and ...

Due in 8 days•Boh Bros. Construction Co., LLC
Road Construction Project in Genesee County

Cadillac Asphalt is seeking bids for a road construction project on Fenton Rd, Grand Blanc Rd, I-75,...

Cadillac Asphalt
Road Construction on M-153 Frains Lake Rd to Napier Rd

Cadillac Asphalt is seeking a subcontractor for road construction on M-153 Frains Lake Rd to Napier ...

Cadillac Asphalt
B23_2026 Proposed Trail Construction

The Virginia Department of Transportation is seeking a prequalified contractor to construct the B23_...

Due in 23 days•Virginia > Virginia Department of Transportation
Scenic Trail Construction

The Virginia Department of Transportation is seeking a prequalified contractor for scenic trail cons...

Due in 23 days•Virginia > Virginia Department of Transportation
Scenic Trail Construction

The Virginia Department of Transportation is seeking a prequalified contractor for scenic trail cons...

Due in 23 days•Virginia > Virginia Department of Transportation
Homerville Bypass Resurfacing Improvements

Clinch County Board of Commissioners is seeking sealed bids for 4.71 miles of resurfacing improvemen...

Due in 22 days•Clinch County
Horace Holmes Drive and Jaguar Trail Road Maintenance

Pike County, Mississippi, is seeking sealed bids for maintenance of 0.370 miles of roadway along Hor...

Due in 10 days•Quitman County > Board of Supervisors
Allen Street Reconstruction

The Massachusetts Department of Transportation is seeking a contractor to reconstruct Allen Street (...

Due in 1 day•Massachusetts > Department of Transportation > Highway Department
CR 35 Bridge and Approaches Construction

Jasper County, Mississippi, is seeking sealed bids for construction of 0.089 miles of bridge and app...

Due in about 3 hours•Jasper County > Board of Supervisors
STSRR Program Project 21-3 Street Improvements

East Baton Rouge Parish is seeking bids for STSRR Program Project 21-3, involving street improvement...

Due in 8 days•City of Baton Rouge > Transportation and Drainage Department > Purchasing Section
Street Construction in Wimbledon Estates, Harveston, and The Highlands

East Baton Rouge Parish is seeking bids for street construction work in Wimbledon Estates, Harveston...

Due in 22 days•East Baton Rouge Parish > Purchasing Section
Highway 94 Rehabilitation from Callander to Highway 17

The Ontario Ministry of Transportation is seeking a contractor to rehabilitate 9.3 km of Highway 94 ...

Due in 4 days•Ontario > Engineering Services – Northeast Region
Leflore County Road Maintenance Project SAP-42(8)M

Leflore County is seeking sealed bids for maintenance of 15.804 miles of non-bridge roads under Stat...

Due in about 3 hours•Leflore County > Board of Supervisors
November 2026 Highway Construction Contracts

The South Carolina Department of Transportation is soliciting electronic bids for highway constructi...

Due in about 1 month•South Carolina > Department of Transportation > Contract Administration
Greene Street Improvements Project

The City of Augusta, Georgia, is seeking bids for improvements to Greene Street between 5th Street a...

Due in 16 days•City of Aiken
Oklahoma Transportation Construction Bid

The Oklahoma Department of Transportation is soliciting bids for an unspecified transportation const...

Due in 25 days•State of Oklahoma > Department of Transportation > Right-of-Way & Utilities Division
Opportunities Near Santa Fe, New Mexico
Investment Management Advisory Services

The New Mexico State Treasurer is soliciting proposals for investment management advisory services u...

Due in 9 days•Los Angeles County
Computer and Information Systems Support Services

The Santa Fe Civic Housing Authority is seeking proposals for computer and information systems suppo...

Albuquerque Housing Authority
Public Records Redaction Software RFI

The New Mexico Self-Insurers' Fund is requesting information from qualified vendors about software t...

Due in 8 days•New Mexico Self-Insurers' Fund
Statewide Water Project Engineering Services

The New Mexico Self-Insurers' Fund is seeking professional engineering services for various water pr...

Due in about 2 months•New Mexico Self-Insurers' Fund
Surface Treatment Aggregate and Water Systems Services

The New Mexico General Services Department is soliciting bids for DOT surface treatment aggregate an...

Due in 22 days•New Mexico Water Service
Enterprise Space Management Consulting Services

The State of New Mexico General Services Department is seeking professional consulting services to d...

Due in 11 days•State of New Mexico > General Services Department > Facilities Management Division
BL-13 Access Management Engineering Consultant Services

The New Mexico Department of Transportation is requesting proposals from qualified firms for enginee...

State of New Mexico > Department of Transportation
CONNECT Network Clinical Guidance and Training Services

Santa Fe County is requesting proposals from qualified licensed professionals or firms to provide cl...

Due in 11 days•Santa Fe County > Community Services Department
Midtown Infrastructure Request for Information

The City of Santa Fe is requesting information regarding Midtown infrastructure through an electroni...

Due in 4 days•City of Santa Fe
Publishing Print New Mexico Official Laws

The New Mexico Compilation Commission is seeking a qualified legal printer to produce the New Mexico...

State of New Mexico > New Mexico Compilation Commission
Emergency Generator Maintenance

The New Mexico Department of Health is seeking emergency generator maintenance services under solici...

Due in 17 days•State of New Mexico
Utility Payment and Customer Communication Services

The City of Santa Fe is seeking proposals for utility payment ecosystem, payment presentment, notifi...

Due in 28 days•City of Santa Fe
Integrated Payment, Point-of-Sale, and Management Systems

Cooperative Educational Services is seeking proposals for integrated payment, point-of-sale, and man...

Due in 11 days•Cooperative Educational Services
Criminal Justice Coordinating Council Coordination Services

The First Judicial District Court of New Mexico is seeking professional Criminal Justice Coordinatin...

Due in 18 days•State of New Mexico > Administrative Office of the Courts > Third Judicial District Court
Public Records Redaction Software RFI

The New Mexico Self-Insurers' Fund is requesting information from qualified vendors about software t...

Due in 8 days•New Mexico Self-Insurers' Fund
Medicaid and Medicare Provider Consultant Services

Santa Fe County is seeking a consultant to provide Medicaid and Medicare provider-enrollment support...

Due in about 2 hours•Santa Fe County > Community Services Department > Purchasing Division
Clinical Guidance and Training Services for the CONNECT Network

Santa Fe County is requesting proposals from qualified licensed professionals or firms to provide Cl...

Due in 11 days•Santa Fe County > Community Services Department
Criminal Justice Coordinating Council Services

The New Mexico First Judicial District Court is requesting proposals to establish a Criminal Justice...

Due in 18 days•State of New Mexico > Administrative Office of the Courts
K-8 Language and Literacy Instructional Materials Adoption

The New Mexico Public Education Department is seeking publishers and providers to submit core and su...

Due in 3 months•State of New Mexico > Public Education Department
2027 K-8 Instructional Materials Adoption

The New Mexico Public Education Department is requesting publishers and providers to submit K-8 Engl...

State of New Mexico > Public Education Department > Instructional Material Bureau
GRO Program Fund Services

The North Central New Mexico Economic Development District is seeking proposals for its GRO Program ...

Due in 21 days•North Central New Mexico Economic Development District
Government Results and Opportunity Program Fund Services and Projects

The North Central New Mexico Economic Development District is seeking multiple New Mexico public ent...

Due in 21 days•North Central New Mexico Economic Development District
District-Wide School-Based Health Center Services

Santa Fe Public Schools is requesting sealed proposals for district-wide school-based health center ...

Due in 10 days•Santa Fe Public Schools
Transportation Construction Project

The New Mexico Department of Transportation is soliciting bids for an unspecified transportation con...

Due in 11 days•State of New Mexico > Department of Transportation
New Mexico Transportation Project

The New Mexico Department of Transportation is soliciting bids for an unspecified transportation pro...

Due in 11 days•State of New Mexico > Department of Transportation
Comments
Correspondences
Custom Fields